SlideShare una empresa de Scribd logo
1 de 111
PROJECT MANAGEMENT OFFICE (PMO)
SETTING UP AND MANAGEMENT
© www.asia-masters.com
Project Management
General Review
© www.asia-masters.com
What is Project Management
• Project Management is the application of skills,
knowledge, tools and techniques to meet the
needs and expectations of stakeholders for a
project.
• The purpose of project management is prediction and prevention, NOT
recognition and reaction
© www.asia-masters.com
Triple Contraint
Quality
Scope
Time
Cost
© www.asia-masters.com
Triple Contraint
• Increased Scope = increased time + increased cost
• Tight Time = increased costs + reduced scope
• Tight Budget = increased time + reduced scope.
© www.asia-masters.com
NATURE OF THE
CONSTRUCTION INDUSTRY
Like Manufacturing industry – Involves the production of a
physical product
Like Service industry – Does not accumulate large amount of
capital
– Many small businesses
Success or failure is highly dependent on the qualities of the people
rather than
Technologies protected by patent
or
Availability of capital facilities
© www.asia-masters.com
CONSTRUCTION INDUSTRY IS
HIGHLY INCENTIVE ORIENTED
• Advances tend to develop from
innovations or “better ideas”
• Cannot be protected by laws of
secrecy or patents
• Ideas disseminate quickly
• Benefit Competitors
• Lack incentive for investment for R&D
© www.asia-masters.com
Owner wants to achieve best value for their
investment
Contractors desire to bid low enough to win but
high enough to realize profit on investment
Workers hope to achieve better living standards
and working conditions
INTEREST GROUPS
© www.asia-masters.com
Owner wants to achieve best value for their
investment
Contractors desire to bid low enough to win but
high enough to realize profit on investment
Workers hope to achieve better living standards
and working conditions
Architect and Engineers are not directly
associated with the above groups
Professional achievement more attractive
INTEREST GROUPS
© www.asia-masters.com
• Know Your Scope of Works
• Understand Your Contractual
Obligations
• Plan Activities in Detail
• Resolve Problems Quickly
• Manage Subcontractors
• Manage Cash Flow
Project Management
Introduction
• The PMBOK is an inclusive term that describes the sum of
knowledge
• within the profession of project management
• PMBOK is applied and advanced by both practitioners and
academics
• PMBOK can be and is being used for projects in various fields of
professions
• including Software engineering
PMP As Construction Management Methodology
© www.asia-masters.com
The Project Management Context
•Project Phases and Project Life Cycle
• Each project is unique enterprise
• Phases can involve a degree of uncertainty
• Each project phase is marked by completion of one or more deliverables
• A deliverable is a tangible, verifiable work product
• The project life cycle serves to define the beginning and the end of a project
•Project Stakeholders
• Are individuals and organizations who are actively involved in the project,
• Whose interests can have positive or negative influence on project execution
and project completion.
(Project manager, Customer, Performing organization, Sponsor)
© www.asia-masters.com
Project Life Cycle
Initiation Phase Definition Phase Planning Phase
Implementation
Phase
Deployment
Phase
Closing Phase
© www.asia-masters.com
Initiation Phase
• Define the need
• Return on Investment Analysis
• Make or Buy Decision
• Budget Development
© www.asia-masters.com
Definition Phase
• Determine goals, scope and project constraints
• Identify members and their roles
• Define communication channels, methods, frequency and content
• Risk management planning
© www.asia-masters.com
Planning Phase
• Resource Planning
• Work Breakdown Structure
• Project Schedule Development
• Quality Assurance Plan
© www.asia-masters.com
Work Breakdown Structure
• For defining and organizing the total scope
of a project
• First two levels - define a set of planned
outcomes that collectively and exclusively
represent 100% of the project scope.
• Subsequent levels - represent 100% of the
scope of their parent node
© www.asia-masters.com
Implementation Phase
• Execute project plan and accomplish project goals
• Training Plan
• System Build
• Quality Assurance
© www.asia-masters.com
Deployment Phase
• User Training
• Production Review
• Start Using
© www.asia-masters.com
Closing Phase
• Contractual Closeout
• Post Production Transition
• Lessons Learned
© www.asia-masters.com
PMBOK 21/15
The Project Management Processes (I)
• Process Groups:
• Initiating processes – recognize when project or phase should begin
• Planning processes – designing and maintaining a scheme which leads to successful
accomplishment of a project
• Executing processes – coordinating people and resources to carry out the plan
• Controlling processes – monitoring and measuring progress and taking corrective actions
when necessary
• Closing processes – analyzing acceptance of the project or phase and bringing it to an end
Links between process groups =>
© www.asia-masters.com
The Project Management Knowledge
Areas
• Project Integration Management
• Ensure that various elements of the project are properly coordinated and integrated
• Processes: Project Plan Development, Project Plan Execution, Overall Change Control
• Project Scope Management
• Ensure that the project includes all the work required,
• And only work required, to complete the project successfully
• Processes: Initiation, Scope Planning, Scope Definition,
Scope Verification, Scope Change Control
• Project Time Management
• Ensure timely completion of the project
• Processes: Activity Definition, Activity Sequencing,
Activity Duration Estimating, Schedule Development, Schedule Control
23/15© www.asia-masters.com
• Project Cost Management
• Ensure that the project is complete within the approved budget
• Processes: Resource Planning,
Cost Estimating, Cost Budgeting, Cost Control
• Project Quality Management
• Ensure that the project will satisfy the requirements
• Processes: Quality Planning, Quality Assurance,
Quality Control
The Project Management Knowledge
Areas (I)
© www.asia-masters.com
The Project Management Knowledge
Areas (II)
• Project Communication Management
• Ensure timely and appropriate generation, collection, storage
• And ultimate disposition of project information
• Processes:
Communications Planning,Information Distribution,
Performance Reporting, Administrative Closure
• Project Risk Management
• Concerned with identifying, analyzing, and responding to project risk.
• Maximizing the results of positive events
• Minimizing the consequences of negative events
• Processes: Risk Identification, Risk Quantification,
Risk Response Development, Risk Response Control
12.05.2009. PMBOK 25/15
The Project Management Knowledge
Areas (II)
• Project Procurement Management
• Acquire goods and services from outside the performing organization
• Processes: Procurement Planning, Solicitation Planning, Solicitation,
Source Selection, Contract Administration, Contract Close-out
• Project Human Resources Management
• Make the most effective use of people involved with the project
• Processes: Organizational Planning,
Staff Acquisition, Team Development
© www.asia-masters.com
• Finally, project managers who are familiar with PMBOK can
custom tailor their project management process to best fit their
company's needs.
Old saying:
“To break the rules, first you have to know the rules. ”
• In the long run, this means that companies will have less of a
reason to outsource when projects require special treatment.
© www.asia-masters.com
– Project Management services for all project phases should be
provided through well established procedures/processes
– Project Management activities span the life of projects beginning
with the conceptual design phase and ending with the defects
liability and occupancy phase
I. Introduction
© www.asia-masters.com
PlanPlan
Monitor &
Control
Monitor &
Control
Close OutClose Out
ImplementImplement
Project Management Approach
InitiateInitiate
© www.asia-masters.com
Major Stakeholders
Major
Stakeholders
Funding Agencies
Authorities
Design
ConsultantsSpecialized
Consultants
Construction
Contractors
Facility
Manager
Client
Supervision
Consultants
End Users
Operators
Project Manager
© www.asia-masters.com
Client
Project
Manager
Consultant
Quantity
Surveyor (CQS)
Supervision
Consultants
Contractors
Design Consultants
Funding AgenciesAuthorities
Expert
Consultants
Operators/End UsersFacility Manager
Communication Chart
© www.asia-masters.com
ma
e
Engineer
Technical
Te
d
Construction
Manager
Packag
ct Control Bo
a
r
ect Director
Consultants’ Local
Office
Proje
oj
E
Engineer
Pr
st
Controllers
IT Specialist
Plann ng
Engineers
Administrative Support
HS C
Engineer
Document
Controllers
Co
E
Manager
Technica
Manager
Project
Controls
Manage
r
Contract
Administrator
QA/Q
C
Manager
Contracts
Manager
HS
t Manager
QA/Q
Client
Head Office SupportHead Office Support
ProjecProject Manager
QA/QC
Manager
Contracts
Manager
HSE
Manager
Technicall
Manager
Project
Controls
Manager
Contract
Administrator
QA/QC
Engineer
Document
Controllers
Cost
Controllers
IT Specialist
Plannini g
Engineers
Administrative Support
Project Manager’s Organisation Chart
HSE
Engineer
Project Director
Consultants’ Local
Office
Project Control Board
Construction
Manager
Package
Engineer
Technical
Team
© www.asia-masters.com
Warehouse
Dept.
Services
Dept.
Admin.
Dept.
Accountant
Cashie
r
nt Manager
Surveyor
Manager
Site
Surveyor(s)
Project Area 2
Manager
Materia
Eng
l
ineer(s)
Tech
n
ci ian(s)
Financia
Manager
Documen
tEngineer
Planning
Engineer
Site
Engineer(s)
meC Engineer ProcureQQA/
& Doc
Manager
Tech
n
ci ian(s)
Contractor’s
Representative
Subcontractors
Subcontractors Project Area 1
Manager
Project Area 1
Manager
Contracting
Manager
Contracting
Manager
A .d min & Logistics
Manager
Admin. & Logistics
Manager
lP ann
i
ng
Planning & Doc
Manager
Technician(s)
Contractor’s Organisation Chart
QA/QC Engineer Procurement Manager
Surveyor
Manager
Site
Surveyor(s)
Project Area 2
Manager
Material
Engineer(s)
Technician(s)
l
Financial
Manager
Document
Engineer
Planning
Engineer
Site
Engineer(s)
Warehouse
Dept.
Services
Dept.
Admin.
Dept.
Accountant
Cashier
© www.asia-masters.com
PM scope can cover:
Project Initiation & Studies
Period
Design Period
Tender & Contracting Period
Construction Period
Defects Liability Period
© www.asia-masters.com
Manage the Construction
© www.asia-masters.com
LIFE CYCLE Construction
Management
Seven Phases
Concept and Feasibility Studies
Preliminary Engineering and Design
Detailed Engineering and Design
Procurement
Construction
Start-up and Implementation
Operation or Utilization
© www.asia-masters.com
1. Concept and Feasibility Studies
Forecast Future Demand
Location
Availability of Resources
Accessibility to transportation
Political and Institutional Factors
Sociological and Economic Impact on
Community
Environmental Impact
Overall Technical and Economic
Feasibility
© www.asia-masters.com
2. Preliminary Engineering and Design
Architectural concepts
Evaluation of technological process alternatives
Size and capacity of facility
Comparative economic studies
Reviews by regulatory bodies for compliance
Zoning regulations
Building codes
Licensing procedures
Safety standards
Environmental impact
Public Hearing
Funding cycles in Legislative and Executive Bodies
3. Detailed Engineering and Design
Design of Architectural Elements
Design of Structural Elements
Site Investigation
Foundation Design
Electrical and Mechanical Design
Preparation of Specifications and Drawings
Preparation of Contract Documents
© www.asia-masters.com
3. Detailed Engineering and Design
Design of Architectural Elements
Design of Structural Elements
Site Investigation
Foundation Design
Electrical and Mechanical Design
Preparation of Specifications and Drawings
Preparation of Contract Documents
Field Construction Methods
Cost Knowledge
© www.asia-masters.com
4. Procurement
Services
Equipment
Materials
© www.asia-masters.com
Services
Equipment
Materials
Lump Sum Contract
Cost Plus Fee Contract
Negotiated Contract
4. Procurement
© www.asia-masters.com
5. Construction
Process whereby the Designer’s Plans and
Specifications are converted into Physical
Structures and Facilities
Co-ordination of all resources to
complete the project
On Schedule
Within Budget
According to Specified Standard of Quality
and Performance
© www.asia-masters.com
6. Start-up and
Implementation
Testing of Components
Warranty Period
© www.asia-masters.com
7. Operation and
Utilization
Regular Maintenance of
Facilities
© www.asia-masters.com
Architect
Interior Designer
Landscape Architect
Civil Engineer
Environmental Engineer
Electrical Engineer
Mechanical Engineer
Chemical Engineer
Geologist
Environmental Scientist
Economist
DESIGN TEAM
General Contractor
Land Surveyor
Formwork Carpenters
Steel Fabricators
Concreters
Bricklayers
Plant and Equipment Operators
Specialist subcontractors
Suppliers
CONSTRUCTION TEAM
© www.asia-masters.com
Construction Contracts
American Institute of Architects
Documents
A101 Standard Form of Agreement between Owner
and Contractor – Stipulated Sum
A111 Standard Form of Agreement between Owner
and Contractor – Cost of the Work Plus a Fee
A201 General Conditions of the Contract for Construction
B141 Standard form of Agreement between Owner
and Architect
A132 Performance Bond and Payment Bond
Elements of a Construction Contract
ARTICLES
Contract Documents
Architect
Owner
Contractor
Subcontractors
Work by Owner or by Separate Contractors
Time of Completion and Extension of Time
Progress and Final Payments
Substantial Completion
Insurance
Changes in the Work
Uncovering and Correction of Work
Termination of Contract
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
General Contractor
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
General Contractor
Subcontractor Subcontractor Subcontractor
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
General Contractor
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
General Contractor
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
Specialists General Contractor
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
Specialists Construction Manager
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
Specialists Construction Manager
General Contractor
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Owner
Architech/Engineer Design Builder
Specialists
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Architech/Engineer Owner
Specialists
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Beneficiary Owner Performance Bond
Principal General Contractor Surety
Subcontractor Subcontractor Subcontractor
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
ORGANIZATIONAL RELATIONSHIPS
Beneficiary Owner Payment Bond
Principal General Contractor Surety
Subcontractor Subcontractor Subcontractor
Beneficiary
2nd Tier Subcontractor
3rd Tier Subcontractor
Supplier
© www.asia-masters.com
INSURANCE
Requirements under AIA
A201Contract Documents
Contractor’s Liability Insurance
Owner’s Liability Insurance
Property Insurance
Loss of Use Insurance
Workmen Compensation
Disability Benefits
© www.asia-masters.com
OWNERS RESPONSIBILITY
Make Financial Arrangements to fulfill his
obligations
Furnish Accurate Contract Specifications and
Drawings for the Contractor’s work
Right to Stop Work
Right to Change Work
Right to Terminate Contract if Contractor
Defaults
© www.asia-masters.com
Architect’s Responsibility
Architect is the Owner’s Representative
Architect is the Administrator of the Contract
Visit site at appropriate stages of construction to
familiarize himself generally with the progress and
quality of the Work and to determine whether Work is
proceeding in accordance with Contract Documents.
Advice the Owner on Work Progress
Guard the Owner against Defects and Deficiencies in
the Work of the Contractor
Reviews Contractor’s Claims and Approves Amount
to be paid to the Contractor
Architect is not responsible for Methods of
Construction or Site Safety
© www.asia-masters.com
Contractor’s Responsibility
Review Contract documents for Errors and
Inconsistencies
Supervise and Co-ordinate all Construction
Work
Provide full time Superintendent on Site
Responsible for Site Safety
Indemnify the Owner against any Claims
by third parties
© www.asia-masters.com
Handling Disputes
Contract is signed between Owner and Contractor
Architect acts as Interpreter of the Contract between Owner
and Contractor
Architect acts as Judge of the Performance of the Owner
and Contractor
All disputes between Owner and Contractor shall be decided
by Architect
Architect shall not show Partiality
Architect’s Decision on Artistic Effects is Final
Arbitration
© www.asia-masters.com
II. Contract/Construction Management
Stage 1: CONSTRUCTION PERIOD
Stage 2: DEFECTS LIABILITY PERIOD (DLP)
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
• Insurance Policies
• Performance Security
• Advance Payment Guarantee
• Notice to Commence
• Communication Procedures
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
• Monitoring Progress
• Evaluating Performance
• Project Management Software
• Logic Network (CPM)
• Short Construction Activities
• Shop Drawings and Materials Submissions
• Procurement Schedules
• Quantity, Duration, Cost, Manpower and
• Equipment
• Resources Schedules and Histograms
• Work Breakdown Structures (WBS)
• Subcontractors’ Schedules
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
• Verify Staked-Out Centerline, Traverse Points, Control Points and Bench Marks
• Adequacy of Borrow Pits and Quarries
• Planned Sources, Supply and Testing of Construction Materials
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
• Site Facilities Adequacy and Organization
• Layout Plan for all Temporary Site Facilities
• Check Site Accesses, Temporary Structures, Site Office, Accommodation, Laboratory,
Stocking Yards, Plant Facilities, Safety Measures, Service Roads, Parking Areas
• Sufficiency, Adaptability, Interconnectivity, Suitability, Organization, Quality,
Performance, Non-Interference with Permanent Works
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
• Clearly Formulated, Well-Documented Method Statement: Method of
Construction, Resources, Safety Precautions, Operation’s Duration
• Submission and Approval before Occurrence of Planned Early Start of
Activities
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
• Monitor Program, Construction Activities, Resources
• Update and Revise Program
• Periodic Co-Ordination Meetings
• Timely Shop Drawings and Samples Submission
• Schedules of Materials and Shop Drawings Submissions
and Approvals tied to Program
• Monitor Labor and Plant Productivity, Materials
Deliveries (Long-Lead Items), Identify Shortages
• Labor, Plant or Materials Deficiencies
• Identify Potential Variance: Scheduled v/s Actual Progress
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
Activity 7
Cost Control
• Interim Payments
• Cash-Flow Estimate
• Implement Variation Orders
• Control & Monitor Quantities and Variation Orders
w.r.t. Contract Price
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
• Project Quality Assurance/Quality Control Plan
• Compliance with Safety and Environment Protection
• Review and Approval of Materials and Shop Drawings
• Inspection of Operations
• Inspection and Testing of Materials and Plant
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
• Inspection of Work before Covering-Up
• “As-Built” Drawings and “Operation and Maintenance Manuals”
• List of Outstanding Works prior to Taking-Over
• Completion of Outstanding Works and Performance during Defects Liability Period
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings &
Record Keeping
• Daily Record of Progress of Works
• Kick-off Site Meeting: Procedures, Means of Communication, Methods for giving Approvals,
Instructions, Variation Orders, etc.
• Regular Site Meetings: Monitor Performance and Progress based on Program, Discuss Problems,
Coordination Issues, etc.
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
and Record
Keeping
• Daily Diary
• Maintain Up-To-Date Information Relevant to Progress, Performance, Quality, Quantities,
Resources & Cost
• Maintain Project Records in Classified and Retrievable Form
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
& Record
Keeping
• Executive Summary
• Section One: General Information
• Section Two: Progress Outline
• Section Three: Schedules
• Section Four: Resource Control
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
and Record
Keeping
• Section Five: Cost Control
• Section Six: Quality Control
• Section Seven: Contract Records
• Section Eight: Progress Photographs
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 11
Claims and
Disputes
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
& Record
Keeping
• Identify Potential Claims
• Settle Disputes or Differences
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning
and Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 11
Claims and
Disputes
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
& Record
Keeping
• Implementation of Methods and
Procedures to Minimize the Potential
Financial and Time Impact of Claims
• Settlement of time/cost claims
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 11
Claims and
Disputes
Activity 12
Completion of
Works /
Taking-Over
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality Control
Activity 9
Site Meetings
& Record
Keeping
II. Contract/Construction Management
stage 1: construction period
• Establish schedule for Testing and Commissioning
• Witness Tests
• Prepare List of Outstanding Works
• Obtain Written Undertaking to Complete any Outstanding Work during DLP
© www.asia-masters.com
Activity 1
Organization
and
Mobilization
Activity 2
Planning and
Program
Activity 3
Survey Check
and Material
Information
Activity 4
Plan for Site
Organization
Activity 5
Construction
Methods
Activity 10
Monthly
Progress
Reports
Activity 11
Claims and
Disputes
Activity 12
Completion of
Works /
Taking-Over
Activity 6
Time Control
Activity 7
Cost Control
Activity 8
Quality
Control
Activity 9
Site Meetings
& Record
Keeping
• Issue Taking-Over Certificate
• Check Progressively “As-built Drawings”
• Review “Operations and Maintenance Manuals”
II. Contract/Construction Management
stage 1: construction period
© www.asia-masters.com
Activity 13
Inspection of
Works
• Inspect and Verify that the Outstanding Works have been Satisfactorily Completed
• Remedy Detected Defects
• Final Taking-Over of Project at End of Defects Liability Period
II. Contract/Construction Management
stage 2: defects liability period
© www.asia-masters.com
Activity 13
Inspection of
Works
Activity 14
Defects Liability
Certificate
• Issuance of Defects Liability Certificate
II. Contract/Construction Management
stage 2: defects liability period
© www.asia-masters.com
Activity 13
Inspection
of Works
Activity 14
Defects Liability
Certificate
Activity 15
Final Certificate
and Final Report
• Final Statement submittal after Issuance of Defects Liability Certificate
• Issuance of Final Certificate
• Final Report
II. Contract/Construction Management
stage 2: defects liability period
© www.asia-masters.com
III. PROJECT CONTROLS
Scope
- Continuous monitoring of actual project performance (Time, Cost,
Quality).
- Assessing performance and any needed corrective/preventive action.
- Maintaining accurate and updated information base through the project’s
cycle.
© www.asia-masters.com
Project Controls Time & Cost
- Review time schedule/cash-flow estimate.
- Review material submittals/shop drawings schedules.
- Record delays and advise on recovery measures.
© www.asia-masters.com
Project Controls
Time & Cost - BENEFITS
Project Controls of the project schedule will enable:
Baseline
– Identifying Project WBS and Baseline Schedule
– Identifying Critical Activities
– Resources Requirements
– Anticipated Cash Flow (S-Curve)
Progress and Update
– Measuring Progress/Performance
– Identifying delays and sources of delay (through further side analysis)
– Assessing the need for rescheduling and determining which activities need to be rescheduled
Changes
– Potential effect of Variation Orders
– Analyzing Contractors’ Claims for Extension of Time
© www.asia-masters.com
PLANNING & SCHEDULING
-Critical Path Method (CPM)
-Critical Path Activities
-Logical Relationships
-Total Float (TF)
-Free Float (FF)
-Constraints
-Resources
© www.asia-masters.com
REPORTS
Resources - Histograms
PLANNING & SCHEDULING
SCHEDULE COMPRESSION
• Shortening the Project Schedule duration without reducing the project scope which
might increase the project cost.
SCHEDULE UPDATE
• Starts with monitoring of the project activities, collecting key progress information
that would be translated into the following at the end of the reporting period (data
date, time now or as of date):
Actual Start of progressing/completed activities
Actual Finish for completed activities
% complete/remaining duration/expected completion date for progressing activities
The above information is entered into the Update Schedule and the schedule
calculation performed.
• The Updated Schedule is compared to the Baseline
Schedule The Critical Path may change.
© www.asia-masters.com
Progress Monitoring & Control
Baseline Vs. Updated Schedule
ESSENTIAL FACTORS
Construction Contract Documents
to specify clearly the requirements
for the construction schedule:
– Category of Software (by name or of similar capabilities)
– Phasing
– Milestones
– WBS
– Interface with other construction projects
– Level of detail
– Short activities duration, quantities and cost (based on
BOQ), resources (labor and equipment)
– Activities to include submittal , approval and
procurement of materials
– Frequency of schedule update and reporting
– Type of reports to be submitted (Logic Network, Bar
Charts, Tabular, Labor Histograms per trade and total,
Equipment Histograms per equipment and total, Cost in
tabular, histogram and S-Curve formats, Earned Value)
– Calendar
© www.asia-masters.com
Project Calendars
A calendar of working days or shifts that establishes those dates on which activities
are worked, and nonworking days.
Nonworking days include holidays.
A project can have a unique calendar or multi-calendars.
Example: Activity with duration of 18 working days.
ESSENTIAL FACTORS
Progress Reporting
Cost Control
• Review and process interim payments
applications
• Monitor quantities and variation
orders
• Monitor cash flow
• Evaluate change/variations impact
• Develop cost forecasts
• Calculate the earned value
• Develop, implement, update project
cost
• Monitor/Identify variances between
actual/budgeted costs
Report
Cost (Value)
Histogram and S – Curve
Earned Value
Specific technique for measuring performance of work based on activities’ costs
BCWS: Budgeted cost of work scheduled (Planned Value)
BCWP: Budgeted cost of work performed (Earned Value)
ACWP: Actual cost of work performed (Actual Cost)
Schedule Variance (SV) = BCWP – BCWS
Cost Variance (CV) = BCWP – ACWP
• Schedule Index (SI) = BCWP/BCWS
• Cost Index (CI) = BCWP/ACWP
© www.asia-masters.com
Planned Value
Earned Value
CV
BCWS
ACWP
SV
BCWP
(BCWS)
(BCWP)
(ACWP)
© www.asia-masters.com
Variation Order - Form
Quality Control
Quality is controlled through the following:
- Timely inspections and testing of works, materials and production plants
- Review and monitoring of Health, Safety and Environment (HSE) plan
- Inspection of material sources and list of suppliers
- Review and Approval of Materials and Shop Drawings
- Review of As-Built drawings and O&M manuals
- Submittal of certificates of guarantee
- Involvement of third party for laboratory testing
- Snag lists implementation
© www.asia-masters.com
Submittal for approval of materials - Form
Request for Inspection - Form
QA/QC Auditing
• Oversee QA/QC implementation
• Oversee inspection/ testing process
• Issue periodic audit reports
© www.asia-masters.com
Document Control
Document Control in construction projects is the management
of contract documents and the incoming and outgoing
correspondence and their attachments and their flow to the
members of the management team for action or information.
Parties involved are commonly:
- Client
- Funding Agency
- Consultant
- Contractor
- Authorities
- Stakeholders
- Other
© www.asia-masters.com
Document Control
Develop/Implement/Maintain Document Control system
to cover:
- Contract Documents
- Correspondence/Minutes of Meetings
- Site Correspondence/Reports
- Drawings Logs
- Submittals
© www.asia-masters.com
Document Control
Primavera Expedition
Global Report
Project Documentation
- A referencing system for all project documents is
necessary to achieve proper document control and archiving.
- Referencing system applies to all documents and
correspondences.
© www.asia-masters.com
XXXXX 001-W 001 1 of 1
Zone No. or Building No.
Discipline (Water Supply)
Serial No. (001)
Project Number X of Y
Referencing System
Example of Drawings Numbering System
© www.asia-masters.com
The End
© www.asia-masters.com

Más contenido relacionado

La actualidad más candente

Project management
Project managementProject management
Project managementSimran Kaur
 
Fundamentals of project management
Fundamentals of project managementFundamentals of project management
Fundamentals of project managementMohamed Amin
 
Setting up a pmo
Setting up a pmoSetting up a pmo
Setting up a pmocrmackenzie
 
Project Management Foundations Course 101 - Project Management Concepts
Project Management Foundations Course 101 - Project Management ConceptsProject Management Foundations Course 101 - Project Management Concepts
Project Management Foundations Course 101 - Project Management ConceptsThink For A Change
 
PMO (Project Management Office)
PMO (Project Management Office)PMO (Project Management Office)
PMO (Project Management Office)Dilawar Abbas
 
Implementing a Project Office Management
Implementing a Project Office ManagementImplementing a Project Office Management
Implementing a Project Office ManagementRicardo Viana Vargas
 
PMO Handbook - How to Plan, Build, and Run a PMO
PMO Handbook - How to Plan, Build, and Run a PMOPMO Handbook - How to Plan, Build, and Run a PMO
PMO Handbook - How to Plan, Build, and Run a PMOAnthony Natoli
 
Project Time Management - PMBOK 5th Edition
Project  Time Management - PMBOK 5th EditionProject  Time Management - PMBOK 5th Edition
Project Time Management - PMBOK 5th Editionpankajsh10
 
Pmo Gap Analysis Sample Itvamp 2008
Pmo Gap Analysis Sample Itvamp 2008Pmo Gap Analysis Sample Itvamp 2008
Pmo Gap Analysis Sample Itvamp 2008ITVAMP, LLC
 
Implementing PMO
Implementing PMOImplementing PMO
Implementing PMOTURKI , PMP
 
Introduction to Project Management
Introduction to Project ManagementIntroduction to Project Management
Introduction to Project ManagementKris Kimmerle
 
Project Management
Project ManagementProject Management
Project ManagementMark Roman
 
PMP Training - 01 introduction to framework
PMP Training - 01 introduction to frameworkPMP Training - 01 introduction to framework
PMP Training - 01 introduction to frameworkejlp12
 
PMO Kick-Off Presentation
PMO Kick-Off PresentationPMO Kick-Off Presentation
PMO Kick-Off PresentationEbru Seiwert
 

La actualidad más candente (20)

Pmo Why?
Pmo Why?Pmo Why?
Pmo Why?
 
Project Management
Project ManagementProject Management
Project Management
 
Project management
Project managementProject management
Project management
 
Fundamentals of project management
Fundamentals of project managementFundamentals of project management
Fundamentals of project management
 
Setting up a pmo
Setting up a pmoSetting up a pmo
Setting up a pmo
 
Project Management Foundations Course 101 - Project Management Concepts
Project Management Foundations Course 101 - Project Management ConceptsProject Management Foundations Course 101 - Project Management Concepts
Project Management Foundations Course 101 - Project Management Concepts
 
PMO (Project Management Office)
PMO (Project Management Office)PMO (Project Management Office)
PMO (Project Management Office)
 
Project Management Concepts
Project Management ConceptsProject Management Concepts
Project Management Concepts
 
Implementing a Project Office Management
Implementing a Project Office ManagementImplementing a Project Office Management
Implementing a Project Office Management
 
PMO Handbook - How to Plan, Build, and Run a PMO
PMO Handbook - How to Plan, Build, and Run a PMOPMO Handbook - How to Plan, Build, and Run a PMO
PMO Handbook - How to Plan, Build, and Run a PMO
 
Project Time Management - PMBOK 5th Edition
Project  Time Management - PMBOK 5th EditionProject  Time Management - PMBOK 5th Edition
Project Time Management - PMBOK 5th Edition
 
PMO-Framework
PMO-FrameworkPMO-Framework
PMO-Framework
 
Pmo Gap Analysis Sample Itvamp 2008
Pmo Gap Analysis Sample Itvamp 2008Pmo Gap Analysis Sample Itvamp 2008
Pmo Gap Analysis Sample Itvamp 2008
 
PMO 101
PMO 101PMO 101
PMO 101
 
The PMO journey
The PMO journeyThe PMO journey
The PMO journey
 
Implementing PMO
Implementing PMOImplementing PMO
Implementing PMO
 
Introduction to Project Management
Introduction to Project ManagementIntroduction to Project Management
Introduction to Project Management
 
Project Management
Project ManagementProject Management
Project Management
 
PMP Training - 01 introduction to framework
PMP Training - 01 introduction to frameworkPMP Training - 01 introduction to framework
PMP Training - 01 introduction to framework
 
PMO Kick-Off Presentation
PMO Kick-Off PresentationPMO Kick-Off Presentation
PMO Kick-Off Presentation
 

Similar a PROJECT MANAGEMENT OFFICE (PMO) SETTING UP AND MANAGEMENT

Project management essentials 3 day training program
Project management essentials   3 day training programProject management essentials   3 day training program
Project management essentials 3 day training programParamjit Arora
 
Fundamentals of aviation project management
Fundamentals of aviation project managementFundamentals of aviation project management
Fundamentals of aviation project managementPartha Chakraborty
 
Introduction to Project Management.pdf
Introduction to Project Management.pdfIntroduction to Project Management.pdf
Introduction to Project Management.pdfdinushikagunawardhan1
 
PROJECT MANAGEMENT AND FINANCE
PROJECT MANAGEMENT AND FINANCE PROJECT MANAGEMENT AND FINANCE
PROJECT MANAGEMENT AND FINANCE S. Sathishkumar
 
Episode 20 :PROJECT MANAGEMENT CONTEXT
Episode 20 :PROJECT MANAGEMENT CONTEXTEpisode 20 :PROJECT MANAGEMENT CONTEXT
Episode 20 :PROJECT MANAGEMENT CONTEXTSAJJAD KHUDHUR ABBAS
 
DISE - Introduction to Project Management
DISE - Introduction to Project ManagementDISE - Introduction to Project Management
DISE - Introduction to Project ManagementRasan Samarasinghe
 
Another Project Hit the wall by Eng Hisham Zeinoun
Another Project Hit the wall by Eng Hisham ZeinounAnother Project Hit the wall by Eng Hisham Zeinoun
Another Project Hit the wall by Eng Hisham ZeinounPMILebanonChapter
 
Project Management Cycle and MS Project 2013 By Subodh Kumar PMP
Project Management Cycle and  MS Project 2013  By Subodh Kumar PMPProject Management Cycle and  MS Project 2013  By Subodh Kumar PMP
Project Management Cycle and MS Project 2013 By Subodh Kumar PMPSubodh Kumar
 
Project lifecycle
Project lifecycleProject lifecycle
Project lifecycleAyo Apampa
 
Proposed Project Management Office
Proposed Project Management OfficeProposed Project Management Office
Proposed Project Management OfficeJosh Folgado
 
2. Project identification.ppt
2. Project identification.ppt2. Project identification.ppt
2. Project identification.pptPedadaSaikumar
 
Skills and tools for project success
Skills and tools for project successSkills and tools for project success
Skills and tools for project successSivaramAthmakuri1
 
Managing the Consulting Engagement
Managing the Consulting EngagementManaging the Consulting Engagement
Managing the Consulting EngagementSaumya Ganguly
 

Similar a PROJECT MANAGEMENT OFFICE (PMO) SETTING UP AND MANAGEMENT (20)

Managing & Supervising Projects, Consultants & Contractors
Managing & Supervising Projects, Consultants & ContractorsManaging & Supervising Projects, Consultants & Contractors
Managing & Supervising Projects, Consultants & Contractors
 
Ibm projectmgmt-1
Ibm  projectmgmt-1Ibm  projectmgmt-1
Ibm projectmgmt-1
 
Project management essentials 3 day training program
Project management essentials   3 day training programProject management essentials   3 day training program
Project management essentials 3 day training program
 
Fundamentals of aviation project management
Fundamentals of aviation project managementFundamentals of aviation project management
Fundamentals of aviation project management
 
Introduction to Project Management.pdf
Introduction to Project Management.pdfIntroduction to Project Management.pdf
Introduction to Project Management.pdf
 
PROJECT MANAGEMENT AND FINANCE
PROJECT MANAGEMENT AND FINANCE PROJECT MANAGEMENT AND FINANCE
PROJECT MANAGEMENT AND FINANCE
 
1. introduction
1. introduction1. introduction
1. introduction
 
Episode 20 :PROJECT MANAGEMENT CONTEXT
Episode 20 :PROJECT MANAGEMENT CONTEXTEpisode 20 :PROJECT MANAGEMENT CONTEXT
Episode 20 :PROJECT MANAGEMENT CONTEXT
 
project introduction.pdf
project introduction.pdfproject introduction.pdf
project introduction.pdf
 
Session 2 mod 2 proj mgt
Session 2 mod 2 proj mgtSession 2 mod 2 proj mgt
Session 2 mod 2 proj mgt
 
DISE - Introduction to Project Management
DISE - Introduction to Project ManagementDISE - Introduction to Project Management
DISE - Introduction to Project Management
 
Another Project Hit the wall by Eng Hisham Zeinoun
Another Project Hit the wall by Eng Hisham ZeinounAnother Project Hit the wall by Eng Hisham Zeinoun
Another Project Hit the wall by Eng Hisham Zeinoun
 
Project Management Cycle and MS Project 2013 By Subodh Kumar PMP
Project Management Cycle and  MS Project 2013  By Subodh Kumar PMPProject Management Cycle and  MS Project 2013  By Subodh Kumar PMP
Project Management Cycle and MS Project 2013 By Subodh Kumar PMP
 
Project lifecycle
Project lifecycleProject lifecycle
Project lifecycle
 
PME UNIT-3.pptx
PME UNIT-3.pptxPME UNIT-3.pptx
PME UNIT-3.pptx
 
Proposed Project Management Office
Proposed Project Management OfficeProposed Project Management Office
Proposed Project Management Office
 
2. Project identification.ppt
2. Project identification.ppt2. Project identification.ppt
2. Project identification.ppt
 
Skills and tools for project success
Skills and tools for project successSkills and tools for project success
Skills and tools for project success
 
Pmi dec 13
Pmi dec 13Pmi dec 13
Pmi dec 13
 
Managing the Consulting Engagement
Managing the Consulting EngagementManaging the Consulting Engagement
Managing the Consulting Engagement
 

Más de Asia Master Training آسيا ماسترز للتدريب والتطوير

Más de Asia Master Training آسيا ماسترز للتدريب والتطوير (20)

Annual training plan 2018 2018
Annual training plan 2018 2018Annual training plan 2018 2018
Annual training plan 2018 2018
 
Human Resource Management : The Importance of Effective Strategy and Planning
Human Resource Management : The Importance of Effective Strategy and PlanningHuman Resource Management : The Importance of Effective Strategy and Planning
Human Resource Management : The Importance of Effective Strategy and Planning
 
Purpose of Contract CloseOuts - Overview Landscape
Purpose of Contract CloseOuts - Overview LandscapePurpose of Contract CloseOuts - Overview Landscape
Purpose of Contract CloseOuts - Overview Landscape
 
Public Meeting - Contract Close-Out - Ground Rules
Public Meeting - Contract Close-Out - Ground RulesPublic Meeting - Contract Close-Out - Ground Rules
Public Meeting - Contract Close-Out - Ground Rules
 
NATIONAL AUDIT – FIDIC CONTRACTS: BASIS OF FAIR CONTRACT
NATIONAL AUDIT – FIDIC CONTRACTS: BASIS OF FAIR CONTRACTNATIONAL AUDIT – FIDIC CONTRACTS: BASIS OF FAIR CONTRACT
NATIONAL AUDIT – FIDIC CONTRACTS: BASIS OF FAIR CONTRACT
 
An Overview of the FIDIC FORMS OF CONTRACT and Contracts Committee Activi...
An Overview of the FIDIC FORMS OF CONTRACT and Contracts Committee Activi...An Overview of the FIDIC FORMS OF CONTRACT and Contracts Committee Activi...
An Overview of the FIDIC FORMS OF CONTRACT and Contracts Committee Activi...
 
OPTICAL INDUSTRY - Design Engineering Fabrication Testing
OPTICAL INDUSTRY - Design Engineering Fabrication TestingOPTICAL INDUSTRY - Design Engineering Fabrication Testing
OPTICAL INDUSTRY - Design Engineering Fabrication Testing
 
Microsoft Word 2010 - Technical Skills Training
Microsoft Word 2010 - Technical Skills TrainingMicrosoft Word 2010 - Technical Skills Training
Microsoft Word 2010 - Technical Skills Training
 
Microsoft® Office Word 2007 Skills & Compentencies Training
Microsoft® Office Word 2007 Skills & Compentencies Training Microsoft® Office Word 2007 Skills & Compentencies Training
Microsoft® Office Word 2007 Skills & Compentencies Training
 
Competency Modeling v. Job Analysis
Competency Modeling v. Job AnalysisCompetency Modeling v. Job Analysis
Competency Modeling v. Job Analysis
 
Competency gaps for Professional Development
Competency gaps for Professional DevelopmentCompetency gaps for Professional Development
Competency gaps for Professional Development
 
Competency Approach to Human Resource Management
Competency Approach to Human Resource ManagementCompetency Approach to Human Resource Management
Competency Approach to Human Resource Management
 
Developing a University-Wide Integrated Employee Core Competency Framework
Developing a University-Wide Integrated Employee Core Competency FrameworkDeveloping a University-Wide Integrated Employee Core Competency Framework
Developing a University-Wide Integrated Employee Core Competency Framework
 
Organizational Change and Development
Organizational Change and DevelopmentOrganizational Change and Development
Organizational Change and Development
 
Competency-based Management for the DoD-wide Contracting Community
Competency-based Management for the   DoD-wide Contracting CommunityCompetency-based Management for the   DoD-wide Contracting Community
Competency-based Management for the DoD-wide Contracting Community
 
COMPETENCY-BASED CURRICULUM DEVELOPMENT - Method & Teaching
COMPETENCY-BASED CURRICULUM DEVELOPMENT - Method & TeachingCOMPETENCY-BASED CURRICULUM DEVELOPMENT - Method & Teaching
COMPETENCY-BASED CURRICULUM DEVELOPMENT - Method & Teaching
 
The Counseling Interview - Principles & Practices
The Counseling Interview - Principles & PracticesThe Counseling Interview - Principles & Practices
The Counseling Interview - Principles & Practices
 
Behavioral Interview - Selecting Quality Employees for a Quality Organization
Behavioral Interview - Selecting Quality Employees for a Quality OrganizationBehavioral Interview - Selecting Quality Employees for a Quality Organization
Behavioral Interview - Selecting Quality Employees for a Quality Organization
 
Effective Hiring Practices - Recruiting the Best Person
Effective Hiring Practices - Recruiting the Best PersonEffective Hiring Practices - Recruiting the Best Person
Effective Hiring Practices - Recruiting the Best Person
 
Industrial & Organisational Psychology Selecting Employees
Industrial & Organisational Psychology Selecting EmployeesIndustrial & Organisational Psychology Selecting Employees
Industrial & Organisational Psychology Selecting Employees
 

Último

Keppel Ltd. 1Q 2024 Business Update Presentation Slides
Keppel Ltd. 1Q 2024 Business Update  Presentation SlidesKeppel Ltd. 1Q 2024 Business Update  Presentation Slides
Keppel Ltd. 1Q 2024 Business Update Presentation SlidesKeppelCorporation
 
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...lizamodels9
 
The CMO Survey - Highlights and Insights Report - Spring 2024
The CMO Survey - Highlights and Insights Report - Spring 2024The CMO Survey - Highlights and Insights Report - Spring 2024
The CMO Survey - Highlights and Insights Report - Spring 2024christinemoorman
 
MAHA Global and IPR: Do Actions Speak Louder Than Words?
MAHA Global and IPR: Do Actions Speak Louder Than Words?MAHA Global and IPR: Do Actions Speak Louder Than Words?
MAHA Global and IPR: Do Actions Speak Louder Than Words?Olivia Kresic
 
Call Us 📲8800102216📞 Call Girls In DLF City Gurgaon
Call Us 📲8800102216📞 Call Girls In DLF City GurgaonCall Us 📲8800102216📞 Call Girls In DLF City Gurgaon
Call Us 📲8800102216📞 Call Girls In DLF City Gurgaoncallgirls2057
 
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...lizamodels9
 
International Business Environments and Operations 16th Global Edition test b...
International Business Environments and Operations 16th Global Edition test b...International Business Environments and Operations 16th Global Edition test b...
International Business Environments and Operations 16th Global Edition test b...ssuserf63bd7
 
2024 Numerator Consumer Study of Cannabis Usage
2024 Numerator Consumer Study of Cannabis Usage2024 Numerator Consumer Study of Cannabis Usage
2024 Numerator Consumer Study of Cannabis UsageNeil Kimberley
 
Intro to BCG's Carbon Emissions Benchmark_vF.pdf
Intro to BCG's Carbon Emissions Benchmark_vF.pdfIntro to BCG's Carbon Emissions Benchmark_vF.pdf
Intro to BCG's Carbon Emissions Benchmark_vF.pdfpollardmorgan
 
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,noida100girls
 
Organizational Structure Running A Successful Business
Organizational Structure Running A Successful BusinessOrganizational Structure Running A Successful Business
Organizational Structure Running A Successful BusinessSeta Wicaksana
 
Case study on tata clothing brand zudio in detail
Case study on tata clothing brand zudio in detailCase study on tata clothing brand zudio in detail
Case study on tata clothing brand zudio in detailAriel592675
 
Independent Call Girls Andheri Nightlaila 9967584737
Independent Call Girls Andheri Nightlaila 9967584737Independent Call Girls Andheri Nightlaila 9967584737
Independent Call Girls Andheri Nightlaila 9967584737Riya Pathan
 
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...lizamodels9
 
APRIL2024_UKRAINE_xml_0000000000000 .pdf
APRIL2024_UKRAINE_xml_0000000000000 .pdfAPRIL2024_UKRAINE_xml_0000000000000 .pdf
APRIL2024_UKRAINE_xml_0000000000000 .pdfRbc Rbcua
 
Global Scenario On Sustainable and Resilient Coconut Industry by Dr. Jelfina...
Global Scenario On Sustainable  and Resilient Coconut Industry by Dr. Jelfina...Global Scenario On Sustainable  and Resilient Coconut Industry by Dr. Jelfina...
Global Scenario On Sustainable and Resilient Coconut Industry by Dr. Jelfina...ictsugar
 
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...lizamodels9
 
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...lizamodels9
 
Buy gmail accounts.pdf Buy Old Gmail Accounts
Buy gmail accounts.pdf Buy Old Gmail AccountsBuy gmail accounts.pdf Buy Old Gmail Accounts
Buy gmail accounts.pdf Buy Old Gmail AccountsBuy Verified Accounts
 

Último (20)

Keppel Ltd. 1Q 2024 Business Update Presentation Slides
Keppel Ltd. 1Q 2024 Business Update  Presentation SlidesKeppel Ltd. 1Q 2024 Business Update  Presentation Slides
Keppel Ltd. 1Q 2024 Business Update Presentation Slides
 
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...
Call Girls In Connaught Place Delhi ❤️88604**77959_Russian 100% Genuine Escor...
 
The CMO Survey - Highlights and Insights Report - Spring 2024
The CMO Survey - Highlights and Insights Report - Spring 2024The CMO Survey - Highlights and Insights Report - Spring 2024
The CMO Survey - Highlights and Insights Report - Spring 2024
 
MAHA Global and IPR: Do Actions Speak Louder Than Words?
MAHA Global and IPR: Do Actions Speak Louder Than Words?MAHA Global and IPR: Do Actions Speak Louder Than Words?
MAHA Global and IPR: Do Actions Speak Louder Than Words?
 
Call Us 📲8800102216📞 Call Girls In DLF City Gurgaon
Call Us 📲8800102216📞 Call Girls In DLF City GurgaonCall Us 📲8800102216📞 Call Girls In DLF City Gurgaon
Call Us 📲8800102216📞 Call Girls In DLF City Gurgaon
 
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...
Lowrate Call Girls In Sector 18 Noida ❤️8860477959 Escorts 100% Genuine Servi...
 
International Business Environments and Operations 16th Global Edition test b...
International Business Environments and Operations 16th Global Edition test b...International Business Environments and Operations 16th Global Edition test b...
International Business Environments and Operations 16th Global Edition test b...
 
2024 Numerator Consumer Study of Cannabis Usage
2024 Numerator Consumer Study of Cannabis Usage2024 Numerator Consumer Study of Cannabis Usage
2024 Numerator Consumer Study of Cannabis Usage
 
Intro to BCG's Carbon Emissions Benchmark_vF.pdf
Intro to BCG's Carbon Emissions Benchmark_vF.pdfIntro to BCG's Carbon Emissions Benchmark_vF.pdf
Intro to BCG's Carbon Emissions Benchmark_vF.pdf
 
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,
BEST Call Girls In Greater Noida ✨ 9773824855 ✨ Escorts Service In Delhi Ncr,
 
Organizational Structure Running A Successful Business
Organizational Structure Running A Successful BusinessOrganizational Structure Running A Successful Business
Organizational Structure Running A Successful Business
 
Case study on tata clothing brand zudio in detail
Case study on tata clothing brand zudio in detailCase study on tata clothing brand zudio in detail
Case study on tata clothing brand zudio in detail
 
Independent Call Girls Andheri Nightlaila 9967584737
Independent Call Girls Andheri Nightlaila 9967584737Independent Call Girls Andheri Nightlaila 9967584737
Independent Call Girls Andheri Nightlaila 9967584737
 
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
 
APRIL2024_UKRAINE_xml_0000000000000 .pdf
APRIL2024_UKRAINE_xml_0000000000000 .pdfAPRIL2024_UKRAINE_xml_0000000000000 .pdf
APRIL2024_UKRAINE_xml_0000000000000 .pdf
 
Global Scenario On Sustainable and Resilient Coconut Industry by Dr. Jelfina...
Global Scenario On Sustainable  and Resilient Coconut Industry by Dr. Jelfina...Global Scenario On Sustainable  and Resilient Coconut Industry by Dr. Jelfina...
Global Scenario On Sustainable and Resilient Coconut Industry by Dr. Jelfina...
 
Corporate Profile 47Billion Information Technology
Corporate Profile 47Billion Information TechnologyCorporate Profile 47Billion Information Technology
Corporate Profile 47Billion Information Technology
 
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
Call Girls In Sikandarpur Gurgaon ❤️8860477959_Russian 100% Genuine Escorts I...
 
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...
Call Girls In Radisson Blu Hotel New Delhi Paschim Vihar ❤️8860477959 Escorts...
 
Buy gmail accounts.pdf Buy Old Gmail Accounts
Buy gmail accounts.pdf Buy Old Gmail AccountsBuy gmail accounts.pdf Buy Old Gmail Accounts
Buy gmail accounts.pdf Buy Old Gmail Accounts
 

PROJECT MANAGEMENT OFFICE (PMO) SETTING UP AND MANAGEMENT

  • 1. PROJECT MANAGEMENT OFFICE (PMO) SETTING UP AND MANAGEMENT © www.asia-masters.com
  • 3. What is Project Management • Project Management is the application of skills, knowledge, tools and techniques to meet the needs and expectations of stakeholders for a project. • The purpose of project management is prediction and prevention, NOT recognition and reaction © www.asia-masters.com
  • 5. Triple Contraint • Increased Scope = increased time + increased cost • Tight Time = increased costs + reduced scope • Tight Budget = increased time + reduced scope. © www.asia-masters.com
  • 6. NATURE OF THE CONSTRUCTION INDUSTRY Like Manufacturing industry – Involves the production of a physical product Like Service industry – Does not accumulate large amount of capital – Many small businesses Success or failure is highly dependent on the qualities of the people rather than Technologies protected by patent or Availability of capital facilities © www.asia-masters.com
  • 7. CONSTRUCTION INDUSTRY IS HIGHLY INCENTIVE ORIENTED • Advances tend to develop from innovations or “better ideas” • Cannot be protected by laws of secrecy or patents • Ideas disseminate quickly • Benefit Competitors • Lack incentive for investment for R&D © www.asia-masters.com
  • 8. Owner wants to achieve best value for their investment Contractors desire to bid low enough to win but high enough to realize profit on investment Workers hope to achieve better living standards and working conditions INTEREST GROUPS © www.asia-masters.com
  • 9. Owner wants to achieve best value for their investment Contractors desire to bid low enough to win but high enough to realize profit on investment Workers hope to achieve better living standards and working conditions Architect and Engineers are not directly associated with the above groups Professional achievement more attractive INTEREST GROUPS © www.asia-masters.com
  • 10. • Know Your Scope of Works • Understand Your Contractual Obligations • Plan Activities in Detail • Resolve Problems Quickly • Manage Subcontractors • Manage Cash Flow Project Management
  • 11. Introduction • The PMBOK is an inclusive term that describes the sum of knowledge • within the profession of project management • PMBOK is applied and advanced by both practitioners and academics • PMBOK can be and is being used for projects in various fields of professions • including Software engineering PMP As Construction Management Methodology © www.asia-masters.com
  • 12. The Project Management Context •Project Phases and Project Life Cycle • Each project is unique enterprise • Phases can involve a degree of uncertainty • Each project phase is marked by completion of one or more deliverables • A deliverable is a tangible, verifiable work product • The project life cycle serves to define the beginning and the end of a project •Project Stakeholders • Are individuals and organizations who are actively involved in the project, • Whose interests can have positive or negative influence on project execution and project completion. (Project manager, Customer, Performing organization, Sponsor) © www.asia-masters.com
  • 13. Project Life Cycle Initiation Phase Definition Phase Planning Phase Implementation Phase Deployment Phase Closing Phase © www.asia-masters.com
  • 14. Initiation Phase • Define the need • Return on Investment Analysis • Make or Buy Decision • Budget Development © www.asia-masters.com
  • 15. Definition Phase • Determine goals, scope and project constraints • Identify members and their roles • Define communication channels, methods, frequency and content • Risk management planning © www.asia-masters.com
  • 16. Planning Phase • Resource Planning • Work Breakdown Structure • Project Schedule Development • Quality Assurance Plan © www.asia-masters.com
  • 17. Work Breakdown Structure • For defining and organizing the total scope of a project • First two levels - define a set of planned outcomes that collectively and exclusively represent 100% of the project scope. • Subsequent levels - represent 100% of the scope of their parent node © www.asia-masters.com
  • 18. Implementation Phase • Execute project plan and accomplish project goals • Training Plan • System Build • Quality Assurance © www.asia-masters.com
  • 19. Deployment Phase • User Training • Production Review • Start Using © www.asia-masters.com
  • 20. Closing Phase • Contractual Closeout • Post Production Transition • Lessons Learned © www.asia-masters.com
  • 22. The Project Management Processes (I) • Process Groups: • Initiating processes – recognize when project or phase should begin • Planning processes – designing and maintaining a scheme which leads to successful accomplishment of a project • Executing processes – coordinating people and resources to carry out the plan • Controlling processes – monitoring and measuring progress and taking corrective actions when necessary • Closing processes – analyzing acceptance of the project or phase and bringing it to an end Links between process groups => © www.asia-masters.com
  • 23. The Project Management Knowledge Areas • Project Integration Management • Ensure that various elements of the project are properly coordinated and integrated • Processes: Project Plan Development, Project Plan Execution, Overall Change Control • Project Scope Management • Ensure that the project includes all the work required, • And only work required, to complete the project successfully • Processes: Initiation, Scope Planning, Scope Definition, Scope Verification, Scope Change Control • Project Time Management • Ensure timely completion of the project • Processes: Activity Definition, Activity Sequencing, Activity Duration Estimating, Schedule Development, Schedule Control 23/15© www.asia-masters.com
  • 24. • Project Cost Management • Ensure that the project is complete within the approved budget • Processes: Resource Planning, Cost Estimating, Cost Budgeting, Cost Control • Project Quality Management • Ensure that the project will satisfy the requirements • Processes: Quality Planning, Quality Assurance, Quality Control The Project Management Knowledge Areas (I) © www.asia-masters.com
  • 25. The Project Management Knowledge Areas (II) • Project Communication Management • Ensure timely and appropriate generation, collection, storage • And ultimate disposition of project information • Processes: Communications Planning,Information Distribution, Performance Reporting, Administrative Closure • Project Risk Management • Concerned with identifying, analyzing, and responding to project risk. • Maximizing the results of positive events • Minimizing the consequences of negative events • Processes: Risk Identification, Risk Quantification, Risk Response Development, Risk Response Control 12.05.2009. PMBOK 25/15
  • 26. The Project Management Knowledge Areas (II) • Project Procurement Management • Acquire goods and services from outside the performing organization • Processes: Procurement Planning, Solicitation Planning, Solicitation, Source Selection, Contract Administration, Contract Close-out • Project Human Resources Management • Make the most effective use of people involved with the project • Processes: Organizational Planning, Staff Acquisition, Team Development © www.asia-masters.com
  • 27. • Finally, project managers who are familiar with PMBOK can custom tailor their project management process to best fit their company's needs. Old saying: “To break the rules, first you have to know the rules. ” • In the long run, this means that companies will have less of a reason to outsource when projects require special treatment. © www.asia-masters.com
  • 28. – Project Management services for all project phases should be provided through well established procedures/processes – Project Management activities span the life of projects beginning with the conceptual design phase and ending with the defects liability and occupancy phase I. Introduction © www.asia-masters.com
  • 29. PlanPlan Monitor & Control Monitor & Control Close OutClose Out ImplementImplement Project Management Approach InitiateInitiate © www.asia-masters.com
  • 31. Client Project Manager Consultant Quantity Surveyor (CQS) Supervision Consultants Contractors Design Consultants Funding AgenciesAuthorities Expert Consultants Operators/End UsersFacility Manager Communication Chart © www.asia-masters.com
  • 32. ma e Engineer Technical Te d Construction Manager Packag ct Control Bo a r ect Director Consultants’ Local Office Proje oj E Engineer Pr st Controllers IT Specialist Plann ng Engineers Administrative Support HS C Engineer Document Controllers Co E Manager Technica Manager Project Controls Manage r Contract Administrator QA/Q C Manager Contracts Manager HS t Manager QA/Q Client Head Office SupportHead Office Support ProjecProject Manager QA/QC Manager Contracts Manager HSE Manager Technicall Manager Project Controls Manager Contract Administrator QA/QC Engineer Document Controllers Cost Controllers IT Specialist Plannini g Engineers Administrative Support Project Manager’s Organisation Chart HSE Engineer Project Director Consultants’ Local Office Project Control Board Construction Manager Package Engineer Technical Team © www.asia-masters.com
  • 33. Warehouse Dept. Services Dept. Admin. Dept. Accountant Cashie r nt Manager Surveyor Manager Site Surveyor(s) Project Area 2 Manager Materia Eng l ineer(s) Tech n ci ian(s) Financia Manager Documen tEngineer Planning Engineer Site Engineer(s) meC Engineer ProcureQQA/ & Doc Manager Tech n ci ian(s) Contractor’s Representative Subcontractors Subcontractors Project Area 1 Manager Project Area 1 Manager Contracting Manager Contracting Manager A .d min & Logistics Manager Admin. & Logistics Manager lP ann i ng Planning & Doc Manager Technician(s) Contractor’s Organisation Chart QA/QC Engineer Procurement Manager Surveyor Manager Site Surveyor(s) Project Area 2 Manager Material Engineer(s) Technician(s) l Financial Manager Document Engineer Planning Engineer Site Engineer(s) Warehouse Dept. Services Dept. Admin. Dept. Accountant Cashier © www.asia-masters.com
  • 34. PM scope can cover: Project Initiation & Studies Period Design Period Tender & Contracting Period Construction Period Defects Liability Period © www.asia-masters.com
  • 35. Manage the Construction © www.asia-masters.com
  • 36. LIFE CYCLE Construction Management Seven Phases Concept and Feasibility Studies Preliminary Engineering and Design Detailed Engineering and Design Procurement Construction Start-up and Implementation Operation or Utilization © www.asia-masters.com
  • 37. 1. Concept and Feasibility Studies Forecast Future Demand Location Availability of Resources Accessibility to transportation Political and Institutional Factors Sociological and Economic Impact on Community Environmental Impact Overall Technical and Economic Feasibility © www.asia-masters.com
  • 38. 2. Preliminary Engineering and Design Architectural concepts Evaluation of technological process alternatives Size and capacity of facility Comparative economic studies Reviews by regulatory bodies for compliance Zoning regulations Building codes Licensing procedures Safety standards Environmental impact Public Hearing Funding cycles in Legislative and Executive Bodies
  • 39. 3. Detailed Engineering and Design Design of Architectural Elements Design of Structural Elements Site Investigation Foundation Design Electrical and Mechanical Design Preparation of Specifications and Drawings Preparation of Contract Documents © www.asia-masters.com
  • 40. 3. Detailed Engineering and Design Design of Architectural Elements Design of Structural Elements Site Investigation Foundation Design Electrical and Mechanical Design Preparation of Specifications and Drawings Preparation of Contract Documents Field Construction Methods Cost Knowledge © www.asia-masters.com
  • 42. Services Equipment Materials Lump Sum Contract Cost Plus Fee Contract Negotiated Contract 4. Procurement © www.asia-masters.com
  • 43. 5. Construction Process whereby the Designer’s Plans and Specifications are converted into Physical Structures and Facilities Co-ordination of all resources to complete the project On Schedule Within Budget According to Specified Standard of Quality and Performance © www.asia-masters.com
  • 44. 6. Start-up and Implementation Testing of Components Warranty Period © www.asia-masters.com
  • 45. 7. Operation and Utilization Regular Maintenance of Facilities © www.asia-masters.com
  • 46. Architect Interior Designer Landscape Architect Civil Engineer Environmental Engineer Electrical Engineer Mechanical Engineer Chemical Engineer Geologist Environmental Scientist Economist DESIGN TEAM
  • 47. General Contractor Land Surveyor Formwork Carpenters Steel Fabricators Concreters Bricklayers Plant and Equipment Operators Specialist subcontractors Suppliers CONSTRUCTION TEAM © www.asia-masters.com
  • 48. Construction Contracts American Institute of Architects Documents A101 Standard Form of Agreement between Owner and Contractor – Stipulated Sum A111 Standard Form of Agreement between Owner and Contractor – Cost of the Work Plus a Fee A201 General Conditions of the Contract for Construction B141 Standard form of Agreement between Owner and Architect A132 Performance Bond and Payment Bond
  • 49. Elements of a Construction Contract ARTICLES Contract Documents Architect Owner Contractor Subcontractors Work by Owner or by Separate Contractors Time of Completion and Extension of Time Progress and Final Payments Substantial Completion Insurance Changes in the Work Uncovering and Correction of Work Termination of Contract
  • 51. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner General Contractor Subcontractor Subcontractor Subcontractor © www.asia-masters.com
  • 52. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner General Contractor Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor © www.asia-masters.com
  • 53. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner General Contractor Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 54. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner Specialists General Contractor Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 55. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner Specialists Construction Manager Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 56. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner Specialists Construction Manager General Contractor Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 57. ORGANIZATIONAL RELATIONSHIPS Owner Architech/Engineer Design Builder Specialists Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 58. ORGANIZATIONAL RELATIONSHIPS Architech/Engineer Owner Specialists Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 59. ORGANIZATIONAL RELATIONSHIPS Beneficiary Owner Performance Bond Principal General Contractor Surety Subcontractor Subcontractor Subcontractor 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 60. ORGANIZATIONAL RELATIONSHIPS Beneficiary Owner Payment Bond Principal General Contractor Surety Subcontractor Subcontractor Subcontractor Beneficiary 2nd Tier Subcontractor 3rd Tier Subcontractor Supplier © www.asia-masters.com
  • 61. INSURANCE Requirements under AIA A201Contract Documents Contractor’s Liability Insurance Owner’s Liability Insurance Property Insurance Loss of Use Insurance Workmen Compensation Disability Benefits © www.asia-masters.com
  • 62. OWNERS RESPONSIBILITY Make Financial Arrangements to fulfill his obligations Furnish Accurate Contract Specifications and Drawings for the Contractor’s work Right to Stop Work Right to Change Work Right to Terminate Contract if Contractor Defaults © www.asia-masters.com
  • 63. Architect’s Responsibility Architect is the Owner’s Representative Architect is the Administrator of the Contract Visit site at appropriate stages of construction to familiarize himself generally with the progress and quality of the Work and to determine whether Work is proceeding in accordance with Contract Documents. Advice the Owner on Work Progress Guard the Owner against Defects and Deficiencies in the Work of the Contractor Reviews Contractor’s Claims and Approves Amount to be paid to the Contractor Architect is not responsible for Methods of Construction or Site Safety © www.asia-masters.com
  • 64. Contractor’s Responsibility Review Contract documents for Errors and Inconsistencies Supervise and Co-ordinate all Construction Work Provide full time Superintendent on Site Responsible for Site Safety Indemnify the Owner against any Claims by third parties © www.asia-masters.com
  • 65. Handling Disputes Contract is signed between Owner and Contractor Architect acts as Interpreter of the Contract between Owner and Contractor Architect acts as Judge of the Performance of the Owner and Contractor All disputes between Owner and Contractor shall be decided by Architect Architect shall not show Partiality Architect’s Decision on Artistic Effects is Final Arbitration © www.asia-masters.com
  • 66. II. Contract/Construction Management Stage 1: CONSTRUCTION PERIOD Stage 2: DEFECTS LIABILITY PERIOD (DLP) © www.asia-masters.com
  • 67. Activity 1 Organization and Mobilization • Insurance Policies • Performance Security • Advance Payment Guarantee • Notice to Commence • Communication Procedures II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 68. Activity 1 Organization and Mobilization Activity 2 Planning and Program • Monitoring Progress • Evaluating Performance • Project Management Software • Logic Network (CPM) • Short Construction Activities • Shop Drawings and Materials Submissions • Procurement Schedules • Quantity, Duration, Cost, Manpower and • Equipment • Resources Schedules and Histograms • Work Breakdown Structures (WBS) • Subcontractors’ Schedules II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 69. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information • Verify Staked-Out Centerline, Traverse Points, Control Points and Bench Marks • Adequacy of Borrow Pits and Quarries • Planned Sources, Supply and Testing of Construction Materials II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 70. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization • Site Facilities Adequacy and Organization • Layout Plan for all Temporary Site Facilities • Check Site Accesses, Temporary Structures, Site Office, Accommodation, Laboratory, Stocking Yards, Plant Facilities, Safety Measures, Service Roads, Parking Areas • Sufficiency, Adaptability, Interconnectivity, Suitability, Organization, Quality, Performance, Non-Interference with Permanent Works II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 71. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods • Clearly Formulated, Well-Documented Method Statement: Method of Construction, Resources, Safety Precautions, Operation’s Duration • Submission and Approval before Occurrence of Planned Early Start of Activities II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 72. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control • Monitor Program, Construction Activities, Resources • Update and Revise Program • Periodic Co-Ordination Meetings • Timely Shop Drawings and Samples Submission • Schedules of Materials and Shop Drawings Submissions and Approvals tied to Program • Monitor Labor and Plant Productivity, Materials Deliveries (Long-Lead Items), Identify Shortages • Labor, Plant or Materials Deficiencies • Identify Potential Variance: Scheduled v/s Actual Progress II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 73. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control Activity 7 Cost Control • Interim Payments • Cash-Flow Estimate • Implement Variation Orders • Control & Monitor Quantities and Variation Orders w.r.t. Contract Price II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 74. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control • Project Quality Assurance/Quality Control Plan • Compliance with Safety and Environment Protection • Review and Approval of Materials and Shop Drawings • Inspection of Operations • Inspection and Testing of Materials and Plant II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 75. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control • Inspection of Work before Covering-Up • “As-Built” Drawings and “Operation and Maintenance Manuals” • List of Outstanding Works prior to Taking-Over • Completion of Outstanding Works and Performance during Defects Liability Period II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 76. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping • Daily Record of Progress of Works • Kick-off Site Meeting: Procedures, Means of Communication, Methods for giving Approvals, Instructions, Variation Orders, etc. • Regular Site Meetings: Monitor Performance and Progress based on Program, Discuss Problems, Coordination Issues, etc. II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 77. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings and Record Keeping • Daily Diary • Maintain Up-To-Date Information Relevant to Progress, Performance, Quality, Quantities, Resources & Cost • Maintain Project Records in Classified and Retrievable Form II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 78. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping • Executive Summary • Section One: General Information • Section Two: Progress Outline • Section Three: Schedules • Section Four: Resource Control II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 79. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings and Record Keeping • Section Five: Cost Control • Section Six: Quality Control • Section Seven: Contract Records • Section Eight: Progress Photographs II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 80. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 11 Claims and Disputes Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping • Identify Potential Claims • Settle Disputes or Differences II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 81. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 11 Claims and Disputes Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping • Implementation of Methods and Procedures to Minimize the Potential Financial and Time Impact of Claims • Settlement of time/cost claims II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 82. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 11 Claims and Disputes Activity 12 Completion of Works / Taking-Over Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping II. Contract/Construction Management stage 1: construction period • Establish schedule for Testing and Commissioning • Witness Tests • Prepare List of Outstanding Works • Obtain Written Undertaking to Complete any Outstanding Work during DLP © www.asia-masters.com
  • 83. Activity 1 Organization and Mobilization Activity 2 Planning and Program Activity 3 Survey Check and Material Information Activity 4 Plan for Site Organization Activity 5 Construction Methods Activity 10 Monthly Progress Reports Activity 11 Claims and Disputes Activity 12 Completion of Works / Taking-Over Activity 6 Time Control Activity 7 Cost Control Activity 8 Quality Control Activity 9 Site Meetings & Record Keeping • Issue Taking-Over Certificate • Check Progressively “As-built Drawings” • Review “Operations and Maintenance Manuals” II. Contract/Construction Management stage 1: construction period © www.asia-masters.com
  • 84. Activity 13 Inspection of Works • Inspect and Verify that the Outstanding Works have been Satisfactorily Completed • Remedy Detected Defects • Final Taking-Over of Project at End of Defects Liability Period II. Contract/Construction Management stage 2: defects liability period © www.asia-masters.com
  • 85. Activity 13 Inspection of Works Activity 14 Defects Liability Certificate • Issuance of Defects Liability Certificate II. Contract/Construction Management stage 2: defects liability period © www.asia-masters.com
  • 86. Activity 13 Inspection of Works Activity 14 Defects Liability Certificate Activity 15 Final Certificate and Final Report • Final Statement submittal after Issuance of Defects Liability Certificate • Issuance of Final Certificate • Final Report II. Contract/Construction Management stage 2: defects liability period © www.asia-masters.com
  • 87. III. PROJECT CONTROLS Scope - Continuous monitoring of actual project performance (Time, Cost, Quality). - Assessing performance and any needed corrective/preventive action. - Maintaining accurate and updated information base through the project’s cycle. © www.asia-masters.com
  • 88. Project Controls Time & Cost - Review time schedule/cash-flow estimate. - Review material submittals/shop drawings schedules. - Record delays and advise on recovery measures. © www.asia-masters.com
  • 89. Project Controls Time & Cost - BENEFITS Project Controls of the project schedule will enable: Baseline – Identifying Project WBS and Baseline Schedule – Identifying Critical Activities – Resources Requirements – Anticipated Cash Flow (S-Curve) Progress and Update – Measuring Progress/Performance – Identifying delays and sources of delay (through further side analysis) – Assessing the need for rescheduling and determining which activities need to be rescheduled Changes – Potential effect of Variation Orders – Analyzing Contractors’ Claims for Extension of Time © www.asia-masters.com
  • 90. PLANNING & SCHEDULING -Critical Path Method (CPM) -Critical Path Activities -Logical Relationships -Total Float (TF) -Free Float (FF) -Constraints -Resources © www.asia-masters.com
  • 92. PLANNING & SCHEDULING SCHEDULE COMPRESSION • Shortening the Project Schedule duration without reducing the project scope which might increase the project cost. SCHEDULE UPDATE • Starts with monitoring of the project activities, collecting key progress information that would be translated into the following at the end of the reporting period (data date, time now or as of date): Actual Start of progressing/completed activities Actual Finish for completed activities % complete/remaining duration/expected completion date for progressing activities The above information is entered into the Update Schedule and the schedule calculation performed. • The Updated Schedule is compared to the Baseline Schedule The Critical Path may change. © www.asia-masters.com
  • 93. Progress Monitoring & Control Baseline Vs. Updated Schedule
  • 94. ESSENTIAL FACTORS Construction Contract Documents to specify clearly the requirements for the construction schedule: – Category of Software (by name or of similar capabilities) – Phasing – Milestones – WBS – Interface with other construction projects – Level of detail – Short activities duration, quantities and cost (based on BOQ), resources (labor and equipment) – Activities to include submittal , approval and procurement of materials – Frequency of schedule update and reporting – Type of reports to be submitted (Logic Network, Bar Charts, Tabular, Labor Histograms per trade and total, Equipment Histograms per equipment and total, Cost in tabular, histogram and S-Curve formats, Earned Value) – Calendar © www.asia-masters.com
  • 95. Project Calendars A calendar of working days or shifts that establishes those dates on which activities are worked, and nonworking days. Nonworking days include holidays. A project can have a unique calendar or multi-calendars. Example: Activity with duration of 18 working days. ESSENTIAL FACTORS
  • 97. Cost Control • Review and process interim payments applications • Monitor quantities and variation orders • Monitor cash flow • Evaluate change/variations impact • Develop cost forecasts • Calculate the earned value • Develop, implement, update project cost • Monitor/Identify variances between actual/budgeted costs
  • 99. Earned Value Specific technique for measuring performance of work based on activities’ costs BCWS: Budgeted cost of work scheduled (Planned Value) BCWP: Budgeted cost of work performed (Earned Value) ACWP: Actual cost of work performed (Actual Cost) Schedule Variance (SV) = BCWP – BCWS Cost Variance (CV) = BCWP – ACWP • Schedule Index (SI) = BCWP/BCWS • Cost Index (CI) = BCWP/ACWP © www.asia-masters.com
  • 102. Quality Control Quality is controlled through the following: - Timely inspections and testing of works, materials and production plants - Review and monitoring of Health, Safety and Environment (HSE) plan - Inspection of material sources and list of suppliers - Review and Approval of Materials and Shop Drawings - Review of As-Built drawings and O&M manuals - Submittal of certificates of guarantee - Involvement of third party for laboratory testing - Snag lists implementation © www.asia-masters.com
  • 103. Submittal for approval of materials - Form
  • 105. QA/QC Auditing • Oversee QA/QC implementation • Oversee inspection/ testing process • Issue periodic audit reports © www.asia-masters.com
  • 106. Document Control Document Control in construction projects is the management of contract documents and the incoming and outgoing correspondence and their attachments and their flow to the members of the management team for action or information. Parties involved are commonly: - Client - Funding Agency - Consultant - Contractor - Authorities - Stakeholders - Other © www.asia-masters.com
  • 107. Document Control Develop/Implement/Maintain Document Control system to cover: - Contract Documents - Correspondence/Minutes of Meetings - Site Correspondence/Reports - Drawings Logs - Submittals © www.asia-masters.com
  • 109. Project Documentation - A referencing system for all project documents is necessary to achieve proper document control and archiving. - Referencing system applies to all documents and correspondences. © www.asia-masters.com
  • 110. XXXXX 001-W 001 1 of 1 Zone No. or Building No. Discipline (Water Supply) Serial No. (001) Project Number X of Y Referencing System Example of Drawings Numbering System © www.asia-masters.com